2025钢结构工程施工合同书用英语.docxVIP

甲方：XXX乙方：XXX20XXCOUNTRACTCOVER专业合同封面RESUME

甲方：XXX

乙方：XXX

20XX

COUNTRACTCOVER

专业合同封面

RESUME

PERSONAL

2025钢结构工程施工合同书用英语

本合同目录一览

1.ContractOverview

1.1ContractualParties

1.2ProjectDescription

1.3ContractDuration

1.4ContractPrice

1.5PaymentTerms

2.ProjectScope

2.1GeneralScope

2.2SpecificWorks

2.3DesignRequirements

2.4CompliancewithRegulations

3.WorkSchedule

3.1ProjectPhases

3.2Milestones

3.3DelaysandExtensions

3.4ProgressReporting

4.QualityControl

4.1QualityStandards

4.2InspectionProcedures

4.3DefectiveWork

4.4RectificationandCompensation

5.MaterialsandEquipment

5.1MaterialSpecifications

5.2SupplierApproval

5.3EquipmentRequirements

5.4MaintenanceandRepair

6.SafetyandHealth

6.1SafetyStandards

6.2HealthandWelfareMeasures

6.3AccidentsandEmergencies

6.4TrainingandInformation

7.EnvironmentalProtection

7.1EnvironmentalRegulations

7.2WasteManagement

7.3PollutionControl

7.4EnvironmentalImpactAssessment

8.IntellectualProperty

8.1OwnershipofWork

8.2PatentsandInventions

8.3ConfidentialityandNonDisclosure

9.Insurance

9.1GeneralLiabilityInsurance

9.2WorkersCompensationInsurance

9.3PropertyInsurance

9.4AdditionalInsurances

10.DisputeResolution

10.1DisputeResolutionMechanism

10.2Arbitration

10.3Litigation

10.4GoverningLaw

11.TerminationandConsequences

11.1TerminationConditions

11.2NoticeofTermination

11.3ConsequencesofTermination

11.4LiquidatedDamages

12.MiscellaneousProvisions

12.1ForceMajeure

12.2AssignmentandSubcontracting

12.3AmendmentsandModifications

12.4GoverningLanguage

13.SignaturesandExecution

13.1PartiesSignatures

13.2ExecutionDate

13.3WitnessSignatures

14.Appendices

14.1Attachments

14.2DrawingsandSpecifications

14.3AdditionalAgr